Loading...
Serving Faribault, MN and surrounding areas. (507) 497-9188
Effective date: January 1, 2026
By accessing or using the website at faribaultdeckandfence.com or by engaging Faribault Deck & Fence for any services, you agree to be bound by these terms and conditions. If you do not agree to these terms, please do not use this website or engage our services. These terms apply to all visitors, customers, and anyone who contacts us through this site.
Faribault Deck & Fence provides residential deck building, fence installation, and related outdoor construction services in Faribault, MN and surrounding communities. Services include, but are not limited to, custom deck design and construction, composite and wood deck installation, fence installation, deck repair and replacement, and related exterior work. All services are subject to a written proposal and signed agreement before work begins.
Written estimates provided by Faribault Deck & Fence are based on the scope of work, materials, and site conditions described or observed at the time of the estimate. Estimates are valid for 30 days from the date issued unless otherwise stated in writing.
Pricing in an estimate may change if the scope of work changes, if unforeseen site conditions are discovered during construction, or if material costs change significantly between the estimate and the start of the project. We will notify you in writing before performing any work that changes the estimated price.
Verbal estimates are not binding. Only written, signed proposals constitute an agreement to perform work at the stated price.
Project start dates are scheduled at the time of contract signing and are subject to availability, weather, permit approval timelines, and material lead times. We will do our best to communicate any changes to the schedule as soon as possible.
If you need to cancel or postpone a project after signing a contract, please notify us in writing as soon as possible. Deposits may be non-refundable if materials have already been ordered or if the cancellation occurs fewer than 14 days before the scheduled start date, as specified in your written agreement.
We reserve the right to reschedule work due to weather conditions, supply delays, or other circumstances beyond our control. We are not liable for delays caused by factors outside our reasonable control.
Payment terms are outlined in your written proposal. In general, a deposit is required before work begins, with the remaining balance due upon project completion. Specific payment milestones for larger projects will be detailed in the written agreement.
All invoices are due upon receipt unless otherwise agreed in writing. Overdue balances may be subject to interest charges as permitted by Minnesota law. We reserve the right to suspend or discontinue work on a project if invoices are not paid as agreed.
We accept payment by check, cash, and other methods as listed on your invoice. Please confirm accepted payment methods at the time of contract signing.
We obtain all required building permits for the projects we build, as required by the applicable municipality. The cost of permits is included in the project proposal unless otherwise specified. Homeowners are responsible for ensuring that the proposed project does not violate any deed restrictions, homeowner association rules, or other private covenants on their property. We are not responsible for delays or costs resulting from permit denials or required modifications due to zoning or HOA restrictions we were not informed of before the project began.
We stand behind our workmanship and will address any defects in construction that arise from our work within a reasonable period after project completion, as specified in your written agreement. Workmanship warranties do not cover damage from normal wear and tear, improper use, alterations made by others, weather events, or failure to follow maintenance recommendations.
Materials and products installed may carry their own manufacturer warranties. We will provide you with any available warranty documentation for materials used on your project. Manufacturer warranties are subject to the terms and conditions of the manufacturer and are separate from our workmanship warranty.
Except as expressly stated in your written agreement, all services are provided "as is" without additional warranties of any kind, express or implied.
To the fullest extent permitted by Minnesota law, Faribault Deck & Fence shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising from or related to our services or your use of this website. This includes, but is not limited to, loss of use, loss of income, or any damages caused by delays beyond our reasonable control.
Our total liability for any claim related to a specific project shall not exceed the total amount paid by you for that project. Some states do not allow certain limitations on liability, so some of the above may not apply to you.
The content on this website - including text, images, and other materials - is provided for informational purposes only. We make no warranties regarding the accuracy or completeness of the information on this site. We reserve the right to update or remove content at any time without notice. You may not reproduce, republish, or redistribute content from this website without our written permission.
If a dispute arises between you and Faribault Deck & Fence, we encourage you to contact us directly first so we can work toward a resolution. Most concerns can be resolved through a direct conversation. If a dispute cannot be resolved informally, both parties agree to attempt mediation before pursuing any other legal remedy. Any legal action not resolved through mediation shall be brought in the appropriate court of Minnesota.
These terms and conditions are governed by and construed in accordance with the laws of the State of Minnesota, without regard to its conflict of law provisions. Any disputes arising under these terms shall be subject to the exclusive jurisdiction of the courts located in Minnesota.
We may update these terms and conditions from time to time. When we do, we will update the effective date at the top of this page. Continued use of this website or our services after changes are posted constitutes your acceptance of the updated terms. We encourage you to review this page periodically.
If you have questions about these terms, please reach out: